Warning: Cannot modify header information - headers already sent by (output started at /home/simplyauto/www/regs/supplycenters/dscr/clause.php:12) in /home/simplyauto/www/includes/site_header.php on line 9
DSCR I34C: GOVERNMENT FIT VERIFICATION TEST, at FARSmarterBids.com

Reference

More Resources

 

DSCR

DSCR I34C: GOVERNMENT FIT VERIFICATION TEST


Deprecated: Function mysql_numrows() is deprecated in /home/simplyauto/www/regs/supplycenters/dscr/clause.php on line 182
Section: I
DPACS Code: I34C
BSM Code: I09F32
Clause Number: 52.209-9G11
Type: LOCAL
Clause last updated: 1996-01
Status: Deleted
Replaced by: this row , this row

Date of text: 1996-01 (current version)
I34C   52.209-9G11   GOVERNMENT FIT VERIFICATION TEST    DSCR (JAN 1996)
AND
I09F32


    (a)  The Contractor shall submit one unit of Lot/Item _____________  
for Government fit verification tests.  The Government fit verification 
tests consist of checking form, fit and function of the item on the 
aircraft at a Government test site.  At least 14 calendar days before 
completion of the unit to be tested, the Contractor shall notify the 
Contracting Officer, in writing, of the anticipated completion date 
so that the Government may coordinate with a Government Test Facility 
for the tests.

    (b)  Upon completing Quality Assurance Representative (QAR) inspection 
on the test unit, the Contractor shall submit the test unit to the 
Government activity provided by the Procuring Contracting Officer.  
The unit shall be shipped with a copy of the DD Form 250, a DD Form 
1222, and marked "GOVERNMENT FIT VERIFICATION TEST:  Contract No __________,
Lot/Item No _______________".  Upon shipment of the unit, the DD Form 250 
and the DD Form 1222 shall be submitted to the Procuring Contracting Officer.

    (c)  Within 60 calendar days after the Government receives the test 
unit, the Contracting Officer shall notify the Contractor, in writing, 
of conditional approval, approval, or disapproval of the Government Fit 
Verification Test.  The notice of conditional approval or approval shall 
not relieve the Contractor from complying with all requirements of the 
specifications and all other terms and conditions of this contract.  
A notice of conditional approval shall state any further action required 
of the Contractor.  A notice of disapproval shall cite reasons for the 
disapproval.

    (d)  If the Government fit verification test is disapproved, the 
Contractor, upon Government request, shall deliver another unit to the 
Government under the terms and conditions and within the time specified 
by the Government.  After a request for an additional unit, the Contractor 
shall make any necessary changes, modifications, or repairs to the unit 
or select another unit for testing.  All costs related to these tests are 
to be borne by the Contractor, including any and all costs for additional 
tests following a disapproval.  The Government shall take action on this 
unit within the time specified in paragraph (c) above.  The Government 
reserves the right to require an equitable adjustment of the contract 
price for any extension of the delivery Schedule, or for any additional 
costs to the Government related to these tests.

    (e)  If the Contractor fails to deliver the test unit on time, or 
the Contracting Officer disapproves the test unit, the Contractor shall 
be deemed to have failed to make delivery within the meaning of the Default
clause of this contract.

    (f)  The test unit submitted to the Government for the Government fit 
verification tests will not be returned to the Contractor to be shipped 
as part of the contract quantity.

    (g)  If the Government does not act within the time specified in 
paragraph (c) above, the Contracting Officer shall, upon timely written 
request from the Contractor, equitably adjust under the changes clause 
of this contract the delivery or performance dates and/or the contract 
price, any other contractual term affected by the delay.

    (h)  Before Government fit verification tests approval, the acquisition 
of materials or components for, or the commencement of production of, the 
balance of the contract quantity is at the sole risk of the Contractor.  
Before Government fit verification tests approval, the costs thereof shall 
not be allocable to this contract for (1) progress payments or 
(2) termination settlements if the contract is terminated for convenience 
of the Government.

    (i)  The Government may waive the requirement for Government fit 
verification test approval where supplies identical or similar to those 
called for in the Schedule have been previously furnished by the offeror/
Contractor and have been accepted by the Government.  The offeror/
Contractor may request a waiver.


Warning: require(/home/simplyauto/www/includes/site_footer.php): failed to open stream: Permission denied in /home/simplyauto/www/regs/supplycenters/dscr/clause.php on line 369

Fatal error: require(): Failed opening required '../../../includes/site_footer.php' (include_path='.:/usr/local/lib/php') in /home/simplyauto/www/regs/supplycenters/dscr/clause.php on line 369